Terms and Conditions

Last Updated: January 15, 2026

These Terms and Conditions are effective as of December 1st, 2025.

These Terms and Conditions ("Terms") constitute a legally binding agreement governing all access to and use of the website operated by Lazo Construction LLC, a Texas limited liability company ("Company," "we," "us," or "our"), including all pages, content, forms, tools, communications, uploads, and features (collectively, the "Site").

By accessing, browsing, submitting information to, or otherwise using the Site, you affirm that you have read, understood, and agree to be bound by these Terms without limitation or qualification. If you do not agree, you must immediately discontinue use of the Site.

1. Website Use Is Informational Only — No Offer, No Contract, No Duty

The Site is provided strictly for general informational and marketing purposes. Nothing contained on the Site shall be construed as:

An offer to perform construction or contracting services
A binding estimate, quote, or proposal
A commitment to pricing, scope, materials, timelines, or availability
Professional advice of any kind
A guarantee of outcomes, results, or compliance

No contractor-client relationship, fiduciary duty, or professional obligation is created by your use of the Site or submission of information. Any services provided by the Company require a separately executed written agreement, signed by all parties.

2. No Reliance; User Assumes All Risk

You expressly acknowledge and agree that:

Any reliance on information found on the Site is unreasonable and at your own risk
Preliminary information may be incomplete, outdated, generalized, or inaccurate
Conditions affecting construction projects change frequently and unpredictably

3. Eligibility, Authority, and Representations

By using the Site, you represent and warrant that:

You are at least eighteen (18) years of age
You are legally capable of entering into binding agreements
You are authorized to submit information regarding any property, project, or entity referenced
Information submitted is truthful, accurate, and complete

4. Permitted and Prohibited Use

You agree not to:

Submit speculative, abusive, fraudulent, or bad-faith inquiries
Use the Site to solicit competing services
Reverse engineer, scrape, or harvest data
Upload viruses, malware, or harmful code
Interfere with Site security, availability, or integrity
Attempt to access restricted systems or data

The Company may suspend or permanently block access without notice for any misuse or suspected misuse.

5. Estimates, Quotes, Pricing, and Scheduling — Explicit Non-Binding Nature

Any estimates, pricing ranges, timelines, or descriptions provided through the Site, email, text, or other digital communication are:

Preliminary only
Subject to change without notice
Based on limited information
Non-binding and non-guaranteed

Final pricing, scope, and scheduling depend on written contracts, site inspections, permits, material costs, labor availability, and third-party performance. The Company is not obligated to honor preliminary figures.

6. Construction Is Inherently Uncertain — Allocation of Risk

You acknowledge that construction and remodeling inherently involve unknown and latent conditions, including but not limited to:

Structural deficiencies
Electrical, plumbing, or mechanical defects
Prior non-code-compliant work
Concealed water intrusion or mold
Hazardous materials (including asbestos or lead)
Soil movement, foundation instability, or drainage issues

The Company shall not be responsible for conditions that are hidden, undiscoverable, or not reasonably identifiable prior to commencement of work.

7. Permits, Inspections, and Governmental Delays

Permitting, inspections, approvals, and governmental actions are outside the Company's control. Delays, rejections, re-inspections, or code changes may occur.

The Company makes no representation or guarantee regarding approval timelines, inspector availability, or governmental outcomes.

8. Subcontractors, Suppliers, and Independent Contractors

The Company may retain subcontractors, suppliers, engineers, inspectors, or other third parties. All such parties are independent contractors. The Company is not liable for delays caused by subcontractors or suppliers, material shortages or substitutions, or acts or omissions of third parties beyond contractual control.

9. Website Content; "As-Is" Disclaimer

THE SITE AND ALL CONTENT ARE PROVIDED "AS IS" AND "AS AVAILABLE." THE COMPANY MAKES NO WARRANTIES, EXPRESS OR IMPLIED, INCLUDING BUT NOT LIMITED TO: ACCURACY, COMPLETENESS, MERCHANTABILITY, FITNESS FOR A PARTICULAR PURPOSE, NON-INFRINGEMENT.

10. Limitation of Liability — Texas-Maximum Protection

TO THE MAXIMUM EXTENT PERMITTED BY TEXAS LAW: THE COMPANY SHALL NOT BE LIABLE FOR ANY INDIRECT, INCIDENTAL, CONSEQUENTIAL, EXEMPLARY, OR PUNITIVE DAMAGES, INCLUDING: LOSS OF PROFITS, DELAYS OR SUSPENSION OF WORK, DIMINUTION IN PROPERTY VALUE, COST OVERRUNS, BUSINESS INTERRUPTION.

Total liability, if any, shall not exceed the amount paid under a written agreement with the Company.

11. Indemnification — Broad and One-Sided

You agree to indemnify, defend, and hold harmless the Company, its members, managers, employees, agents, and subcontractors from any claims, damages, liabilities, losses, costs, or expenses (including attorneys' fees) arising out of your use or misuse of the Site, information you submit, violations of these Terms, or violations of law or third-party rights.

12. Communications; No Confidentiality

All communications through the Site are deemed non-confidential. Do not submit sensitive, proprietary, or confidential information unless expressly requested and contractually protected.

13. Force Majeure — Broadly Defined

The Company shall not be liable for delays or failures caused by events beyond its reasonable control, including but not limited to: severe weather, natural disasters, labor disputes, supply chain disruptions, government actions or emergencies, utility outages, pandemics or public health events.

14. Binding Arbitration and Class Action Waiver

PLEASE READ THIS SECTION CAREFULLY. IT AFFECTS YOUR LEGAL RIGHTS.

Any dispute, claim, or controversy arising out of or relating to these Terms, the Site, or any services provided by the Company shall be resolved by binding arbitration administered by the American Arbitration Association ("AAA") in accordance with its Commercial Arbitration Rules. Arbitration shall take place in the State of Texas.

CLASS ACTION WAIVER: You agree that any arbitration or legal proceeding shall be conducted only on an individual basis and not as a class action, collective action, or representative action. You expressly waive any right to participate in a class action lawsuit or class-wide arbitration against the Company.

15. Governing Law, Venue, and Jurisdiction

These Terms are governed by the laws of the State of Texas, without regard to conflict-of-law principles. To the extent any dispute is not subject to arbitration, it shall be brought exclusively in a state or federal court located within Texas.

16. Attorneys' Fees and Costs

In any dispute arising from these Terms or use of the Site, the prevailing party shall be entitled to recover reasonable attorneys' fees, court costs, and expenses.

17. Severability and Enforcement

If any provision is found unenforceable, the remaining provisions shall remain in full force. Failure to enforce any provision does not constitute waiver.

18. Modifications and Continued Use

The Company may modify these Terms at any time without notice. Continued use of the Site constitutes acceptance of any modifications.

19. Entire Agreement

These Terms constitute the entire agreement regarding use of the Site and supersede all prior communications.

20. Intellectual Property

All content on the Site, including but not limited to text, images, photographs, graphics, logos, trademarks, trade dress, page layout, and design elements, is the exclusive property of the Company or its licensors and is protected by United States and international copyright, trademark, and other intellectual property laws.

You may not reproduce, distribute, modify, create derivative works from, publicly display, republish, download, store, transmit, or otherwise use any content from the Site without the prior written consent of the Company, except for temporary caching or as necessary to view the Site for personal, non-commercial use.

21. Contact Information

Questions regarding these Terms may be submitted through the Site's contact form or directed to:

Lazo Construction LLC
Email: legal@lazoconstructiontx.com